scholarly journals Delay and cost overrun in road construction projects in Jordan

2015 ◽  
Vol 4 (2) ◽  
pp. 288 ◽  
Author(s):  
Nabil Al-Hazim ◽  
Zaydoun Abusalem

This study aims to identify the most important factors that cause delay in road construction projects in Jordan, which results in cost and time overrun allocated for this type of engineering projects and cause critical problems for both the developer and the contractor. The gap between the cost at completion and that originally estimated, known as cost overrun, can be regarded as one of the most important parameters reflecting the success of projects. In the public sector, money spent on project change orders results in increased construction time which in return reduces the number and size of the projects that can be completed during any given fiscal year. To achieve this goal, the documents and the final reports for several sample projects implemented over the years 2000 to 2008 were analyzed. All the projects were administered by the same organization taken from Jordan Ministry of Rural and Public Works. The results of this study can assist highway officials in their design, planning, scheduling and projects completions so that necessary actions can be taken to control these overruns in future projects. The study showed that 19 factors might cause delays of road construction projects as defined through a detailed literature review. The analysis of the study indicated that the top causes affecting time and cost overrun in road construction projects in Jordan are Terrain and Weather conditions.

Author(s):  
Mega Waty ◽  
Hendrik Sulistio

A Change Order is a written and legal work order that changes the scope of the original contract, with compensation that has been agreed upon by the owner and the contractor. Changes can be in the form of adding or reducing the scope of work, changing materials, or changing schedules. Change Order causes the cost of contract items to swell, planning errors and negligence as well as changes in scope that can be reduced by sharpening planning results. The scope of research on road construction in Indonesia, especially in DKI Jakarta and Banten provinces. This study aims to determine the identification of change orders in road construction projects. Data obtained from real data on road construction projects from 2013-2018 on 16 road construction project packages in the form of road construction project addendum contracts. Based on the addendum contract, added work, less work, addition of new items and removal of work items are determined. The identification of change order risk is seen from three aspects, namely the addition and reduction of work items, the removal of items and the addition of new items and the wishes of the owner, thereby increasing the cost of the change order contract. This study found 732 changes in construction work items. Risk identification is obtained from the frequency of changes above 35% which is an intermediate frequency that tends to increase the occurrence of change orders. The results of risk identification were obtained for 31 construction work items, the highest percentage was for Thermoplastic Road Marking work, followed by 30 other construction work items. Keywords: risk identification; change orders; road construction projects  AbstrakChange Order adalah perintah kerja tertulis dan sah  yang mengubah lingkup kontrak semula, dengan kompensasi  yang sudah disetujui oleh pemilik dan  kontraktor.  Perubahan dapat berupa penambahan atau pengurangan lingkup pekerjaan, perubahan material, atau perubahan jadwal. Change Order menyebabkan biaya  item kontrak membengkak, kesalahan perencanaan dan kelalaian serta perubahan ruang lingkup yang dapat dikurangi dengan mempertajam hasil perencanaan.. Lingkup penelitian pada konstruksi jalan di Indonesia khususnya  provinsi DKI Jakarta dan Banten. Penelitian  bertujuan untuk  mengetahui  identifikasi change order proyek konstruksi jalan. Data didapat dari data riil proyek konstruksi jalan dari tahun 2013- 2018 pada 16 paket proyek konstruksi jalan berupa kontrak addendum proyek konstruksi jalan. Berdasarkan kontrak addendum maka ditentukan pekerjaan tambah, pekerjaan kurang, penambahan item baru dan penghilangan item pekerjaan. Identifikasi risiko change order dilihat dari tiga aspek yakni penambahan dan pengurangan item pekerjaan, penghilangan item dan penambahan item baru dan keinginan dari pihak owner sehingga meningkatkan biaya kontrak change order.  Penelitian ini mendapatkan 732 perubahan  item pekerjaan konstruksi.  Identifikasi risiko didapat dari  frekuensi perubahan diatas 35% yang merupakan frekuensi menengah yang cenderung meningkatkan terjadinya change order. Hasil identifikasi risiko didapat pada  31 item pekerjaan konstruksi, yang tertinggi persentase pada pekerjaan  Marka Jalan Termoplastik, diikuti 30 item pekerjaan konstruksi lainnya.


2020 ◽  
Vol 3 (1) ◽  
pp. 199
Author(s):  
Alexander Junius ◽  
Mega Waty

In a construction project, changes during the construction period are common. This change can be in the form of an increase or decrease in volume and type of work, changes in work specifications, or changes in the schedule for implementation. Changes in projects are often known as change orders. Change orders must be approved by all parties in a project namely, contractors, owners, and consultants. Change orders are caused by several factors such as changes in design, delays in procurement of goods, differences in field conditions, and others. The impact of this change order is felt by all parties involved in a project, but the change order has a different impact on each party involved. This study aims to determine the biggest impact of change orders from the contractor. In the questionnaire submitted the impact of change order is divided into several variables namely, the cost of quality, time, organization, and others. From the responses of respondents regarding the impact of change orders on road construction projects, an analysis was performed with the calculation of the Relative Importance Index (RII), and the biggest impact was obtained. Before the data is processed with RII, the validity and reliability tests are performed first. The biggest impact of change orders caused by change orders is that change orders increase the budget for contractors, change orders increase overhead costs, increase project duration, cause project costs overruns, and change orders cause a decrease in project profits. AbstrakPada suatu proyek konstruksi, perubahan selama masa konstruksi merupakan hal yang umum terjadi. Perubahan ini bisa berupa penambahan atau pengurangan volume dan jenis pekerjaan, perubahan spesifikasi pekerjaan, maupun perubahan jadwal pelakasnaan. Perubahan dalam proyek sering dikenal change order. Change order harus disetujui oleh semua pihak yang ada dalam suatu proyek, yaitu kontraktor, pemilik, dan konsultan. Change order disebabkan oleh beberapa faktor seperti perubahan desain, keterlambatan pengadaan barang, perbedaan kondisi lapangan, dan lain-lain. Dampak dari change order ini dirasakan seluruh pihak yang terlibat dalam suatu proyek, namun change order menimbulkan dampak yang berbeda pada tiap pihak yang terlibat. Penelitian ini bertujuan untuk mengetahui dampak change order terbesar dari pihak kontraktor. Dalam kuesioner yang diajukan dampak change order dibagi menjadi beberapa variabel yaitu, biaya mutu, waktu, organisasi, dan lainnya. Dari hasil tanggapan responden mengenai dampak change order pada proyek konstruksi jalan, dilakukan analisis dengan perhitungan Relative Importance Index (RII), dan didapat dampak terbesar. Sebelum data diolah dengan RII dilakukan uji validitas dan uji reliabilitas terlebih dahulu. Dampak change order terbesar yang ditimbulkan oleh change order adalah change order menambah anggaran untuk kontraktor, change order meningkatkan biaya overhead, menambah durasi proyek, menyebabkan biaya proyek membengkak, dan change order menyebabkan penurunan keuntungan proyek.


Author(s):  
Ahmed Salem Ahmed Marey Alhammadi ◽  
◽  
Aftab Hameed Memon ◽  

UAE construction industry frequently faces poor cost performance which commonly known as cost overrun problem. This problem is resulted from several factors and it is important to identify these cost overrun factors in order to avoid and minimize it. Hence, this paper focused on determined the relevancy of factors affecting cost performance in construction projects of UAE. Through a review of past research works conducted globally, 27 factors of cost overrun were listed and used for developing a structured questionnaire. A survey was conducted with 33 practitioners from client, consultant and contractors organizations involved in handling construction projects in UAE. The respondents were requested to state their perception regarding the relevancy of each of the factors that was perceived in context with cost overrun issue using 5-points Likert scale. The responses were analysed using average index method and the results found that all the 27 factors are relevant with construction industry of UAE in causing cost overrun. These factors can be used for further investigation to uncover critical problems of cost overrun.


2020 ◽  
Vol 12 (1) ◽  
pp. 54-65
Author(s):  
Tariku Nigussie ◽  
M.K. Chandrasekar

Rebar is one of the materials which is so scarce and highly expensive. The existing practices produce a large quantity of wastage; which contributes to the increment of the project cost. This study aimed to analyze the causes, extent, and remedies of steel wastages on the total costs of construction projects in Hawassa city. The study followed descriptive and analytical research designs. The cost estimated in the bill of quantity and the final cost after the provision of the steel with alterations was compared and the reasons for cost overrun were analyzed. The data were analyzed using Central value analysis, correlation and regression analysis using SPSS stat20, RebarWin7.97, ETABS2016. The percentage of the cost of steel wastage in total cost was found 1.43%. The result of the study verdict that frequent design change and bare-benders skill gap contribute much to the material wastage, thus for the cost overrun of projects. Keywords: Bending gain, cost overrun, detailing, rebar, redesign, steel, wastage


Author(s):  
Octavio P.M Marques ◽  
I M. Alit K. Salain ◽  
I W. Yansen

Building project as one of the construction services are filled with varying risks during the construction phase of the project implementation. At the stage of the project implementation, risks may arise either the risk of time, cost and those which affect the quality of the project. Therefore, we need to understand the risks at the construction phase and mitigation to the risks to meet in execution of project based on initial planning. The study was conducted to identify the risks in the implementation of construction projects of government buildings by using survey methods that aim to get the opinion of the respondents regarding the risks at implementation of the government building construction projects in the city of Dili - Timor Leste. Further, it was done a risk assessment to determine the major or main risks. Major risk is controlled through mitigation measures and allocation of risks to the parties directly involved in construction projects such as Project Owner, Technical Supervisor, Consultant Design, Consultant Supervision and Contractor. The analysis used in this study is a qualitative analysis. The results showed 64 risks identified in the implementation of construction projects there are 10 government buildings risks (16%) with an unacceptable category, 18 risks (28%) with the undesirable category, 28 risks (44%) with acceptable category and 8 risks (12%) with negligible category. Ownership of major / main risk to the parties directly involved in the implementation of construction projects such as the project owner, technical supervisor, consultant design, consultant supervision and contractors. The project Owner and Technical Supervision (Department of Public Works) is expected to further enhance the ability to manage projects so not throwing responsibility in managing government projects. consultant design and sonsultant supervision to be more careful in design till supervision during the implementation period so as to meet the cost, quality and time planned. Contractors are expected to further improve the performance of the building construction project.


Author(s):  
Manu Noushad ◽  
Anu V. Thomas ◽  
Ramaswamy K. P

Construction projects experience claims and disputes due to increased complexity of contract documentation, which subsequently affects the cost performance of projects. Majority of the previous studies on disputes and cost overrun have mainly focused on finding the causes of cost overrun or disputes in the industry. Identification of dispute prone areas and the associated range of cost overrun due to the disputes are less explored. Previous research findings indicate that the various factors resulting in cost overrun itself are the causes of disputes. It is necessary to understand, assess and take appropriate actions for increasing the predictability of claims and disputes in order to improve the cost performance of construction projects. In this study, an attempt is made to identify and prioritize the dispute prone areas in Indian construction projects by analytical hierarchy process (AHP).


2021 ◽  
Vol 23 (05) ◽  
pp. 797-805
Author(s):  
Neelakash Haloi ◽  
◽  
Tapas Goyal ◽  
Faizan Zahoor ◽  
Harsh Jain ◽  
...  

In recent years, the impact of the construction industry on the economy of India is increasing. However, there are a number of problems that are being faced by the construction companies or contractors or other relevant stakeholders, in the completion of a construction project. One of the major problems being faced is time and cost overrun. Thus, it is important to find ways of mitigating this critical problem. One of the solutions that is being used is the prediction of the amount and time that a project might overrun beforehand i.e. estimating the overrun during the design phase itself. This prediction can be done using a number of different techniques, the important one of which used in this paper is through the use of Fuzzy Logic. It also provides a brief description about the factors that are responsible for causing this cost overrun. The factors are identified by conducting a questionnaire survey and gathering responses from the relevant stakeholders which include contractors, project engineers, architects and consultants. The responses collected are further processed and analysed using SPSS software. The top 5 factors have been selected after the analysis and further used in preparation of the fuzzy logic model in the fuzzy toolbox of MATLAB. Further, the validation of this model has been done with real-time data of projects from various published research papers. Thus, the model developed provided prediction of the percentage of the cost overrun based on the percentage input of the top five factors.


2020 ◽  
Vol 11 (4) ◽  
pp. 1184
Author(s):  
Ashem Emmanuel Egila ◽  
Oluwaseun Abdulakeem Balogun ◽  
Saheed Olanrewaji Yusuf

Poor road infrastructure in Nigeria is a significant challenge, just like poverty, insecurity, and unemployment. The construction of road in the country is characterized by numerous challenges throughout the project life cycle. Some of these challenges are project delay and cost overrun, corruption and fraud, faulty contractual process among others. Objectives of this study are to identify factors influencing delays and cost overruns in road construction project, to rank these factors base on their impacts and importance, and to suggest conservative ways to address the future challenges that can result from delays and cost overruns of future road construction projects. The research instruments include in-depth literature review, fieldwork, questionnaire administration, and interview. Inferential statistics such as Relative importance index (RII) and Mean Value techniques were used to analyze collected data. The result of the study identified factors influencing delays and cost overruns in road construction projects as; man related, money-related, machine-related, material related, environmental-related, and method related factors. Analysis using RII and MV ranked man and money related as the highest factors for delay and cost overrun respectively. Hence, the research recommends that the Government should create an enabling environment, making suitable policy for the construction company to operate.


Author(s):  
Christian Hofstadler

Construction time has a major influence both on the cost-efficient execution of construction works and on the overall project outcome achieved by the client. Clients would do themselves a disservice if they specified short or extremely short construction periods for their projects. The same applies to time made available for project preparation, particularly for the design and tender stages. Any project that is poorly planned, tendered, and executed under time pressure will adversely affect actual construction work but also the building’s use and possible reuse. Cost, time and quality targets are at risk due to the resulting disruptions to the construction process. Productivity is adversely affected not only by unduly short but also exceedingly long construction times. Short or very short construction times have a major influence on the efficient and effective utilization of production factors, including elementary (workforce, materials, equipment and machinery) and discretionary factors (project manager, site manager, technicians, etc.). This paper outlines the basic correlation between construction time, labor consumption rates and productivity as well as construction cost. Furthermore, it sets out to determine the influence of construction time on costing and, consequently, on the construction process. A practical example demonstrates how normal construction time can be calculated for reinforced concrete works based on uncertain input parameters. In addition, the benefits of specifying normal construction time for clients and contractors are outlined.


2012 ◽  
Vol 12 (1) ◽  
pp. 58-71 ◽  
Author(s):  
Ibrahim Mahamid ◽  
Amund Bruland

This paper investigates the statistical relationship between actual and estimated cost of road construction projects using data from road construction projects awarded in the West Bank in Palestine over the years 2004–2008. The study is based on a sample of 169 road construction projects. Based on this data, regression models are developed. The findings reveal that 100% of projects suffer from cost diverge, it is found that 76% of projects have cost under estimation while 24% have cost over estimation. The discrepancy between estimated and actual cost has an average of 14.6%, ranging from -39% to 98%. The relation between the project size (length and width) and the cost diverge is discussed.


Sign in / Sign up

Export Citation Format

Share Document